TERMS OF ENGAGEMENT
These terms of engagement together with the Fee Submission Form constitute the entire Agreement between the Client and 2x4 Engineering Design Pty Ltd ACN 685 545 073, ABN 32 685 545 073 (2x4, us, our or we). If there is any inconsistency between the Fee Submission Form and this Agreement, the Fee Submission Form overrides the provisions of the Agreement to the extent of the inconsistency.
PART A – PERFORMANCE OF THE SERVICES
A1 2x4 shall perform the Services with due care, skill and diligence and in accordance with the standard performance considered acceptable by the consulting engineering profession in Australia.
A2 2x4 shall communicate with the Client by and through 2x4 Representative, who shall have authority to bind 2x4 in respect of all matters arising out of or in connection with the Agreement.
A3 Unless otherwise agreed in writing, 2x4 may rely on and treat the Documentation and the directions provided by the Client as accurate and correct. 2x4 is not liable for errors arising from inaccurate or incomplete information supplied by the Client. 2x4 shall notify the Client if and to the extent 2x4 becomes aware that any information provided by the Client contains an ambiguity, error, omission, discrepancy, insufficiency or inconsistency or is otherwise inefficient to enable 2x4 to perform the Services.
A4 If 2x4 becomes aware of any matter that will change the scope, character, quality, sequence or timing of the Services, then 2x4 shall promptly notify the Client of that matter.
A5 2x4 will provide what it considers to be industry standard designs (based on economy of construction and its experience with similar projects), unless instructed otherwise. Such instructions may involve a variation of our scope of work and additional fees. Calculations will be produced to satisfy our internal QA systems, but will not be issued to third parties for review unless agreed otherwise.
A6 Changes that require redesign and/or change in the scope of the Services may attract additional charges and we will advise you of these costs. Where the Client requests additional services from 2x4 that are not included in the original scope of services forming this Agreement, 2x4 is not obliged to proceed with such additional work until a revised Agreement or fee variation is in place. This includes (but is not limited to) abortive work which arises due to fast-tracking the project prior to approvals or other design inputs being inadequately defined (e.g. commencing design development prior to development approval, commencement of detailed design prior to tenancy briefing, document issue prior to full co-ordination of all disciplines etc.). Should you require us to stop work for any reason, 2x4 will issue an invoice for the work (or part thereof) completed up to that date, which must be paid within the normal payment terms. Work stoppage does not relieve the Client of any payment obligations for completed Services.
A7 Unless noted otherwise within this Agreement, an allowance for visits to site to inspect work compliance with our design have been included in the Fee, however this should be considered an estimate only. Whilst we will make reasonable efforts to complete our works within this allowance, we will be entitled to an adjustment where events or matters factors beyond our control (e.g. redesign due to latent site conditions or construction errors, poor contractor communications or performance) affect the performance of the Services.
A8 At the request of the Client, 2x4 may express an opinion of probable cost of the Project. The probable cost is based on 2x4’s experience as a consulting engineer and not as a quantity surveyor. The Client accepts and acknowledges the estimate is merely a guide and 2x4 accepts no liability for these estimates.
PART B – CLIENT RESPONSIBILITY
B1 The Client shall promptly provide 2x4 with all relevant Documentation and instructions necessary and other information to enable 2x4 to provide the Services.
B2 The Client shall communicate with 2x4 by and through the Client’s Representative, who shall have authority to bind the Client in respect of all matters arising out of or in connection with the Agreement.
B3 If the Client becomes aware of any matter that will change the scope, character, quality, sequence or timing of the Services, then the Client shall promptly notify 2x4 of that matter.
B4 The Client shall ensure that adequate public liability and contract works insurances are obtained and maintained for the course of the Project.
B5 In a multi-disciplinary environment, overall co-ordination of the Project will be undertaken by the Client Representative.
B6 A contract superintendent engaged by the Principal will be responsible for administering the contract. (If 2x4 are not engaged for this service.)
B7 All consultants’ drawings in respect of the Project will be made available to us in Autodesk Revit or AutoCAD compatible electronic format.
B9 The project as described will not change significantly in extent, scope or budget.
PART C – PAYMENT TO 2X4 FOR THE SERVICES
C1 Unless agreed otherwise in writing, 2x4 shall issue progress claims at monthly intervals and the Client shall pay each claim in full within 30 days of the date of the claim by cash, or by cheque, or by bank cheque, or by direct credit, or by any other method as agreed to between the Client and 2x4. If any payment remains unpaid beyond 30 days, 2x4 reserves the right to suspend all further work until payment is received.
C2 The Client shall pay all reasonable costs and expenses (including, without limitation, legal costs on an indemnity basis) incurred by 2x4 in pursuing any overdue payments.
C3 The Client shall pay 2x4 the Fee and, unless stated otherwise, the Reimbursable Expenses, which will be charged at cost plus 10%, and may be invoiced by 2x4 as incurred
C4 2x4 reserve the right to charge interest on overdue accounts on the daily overdue balance at the rate of 12.5% per annum.
C5 2x4 reserve the right to charge for additional drawings in excess of 10 sets.
PART D – HOURLY RATES
D1 The Client agrees to pay 2x4 the Fee described in the Fee Submission Form.
D2 The Fee in the Fee Submission Form is valid for the duration of the works provided works are commenced within 6 months of acceptance and completed with 12 months of acceptance. 2x4 reserve the right to review their position in relation to Fees should works not commence within this period. Any variation to the Fee will be notified in writing to the Client.
D3 If the Fee or a means of calculating the Fee is not specified in the Fee Submission Form or if a variation is required, then the Fee shall be calculated using the schedule of rates.
D4 If the Client varies the scope, character, quality, sequence or timing of the Services, then 2x4 may vary the Fee accordingly.
D4 All amounts expressed or determined to be payable under this Agreement are calculated and will be determined exclusive of GST unless otherwise expressly stated that GST is included.
PART E – SCOPE OF LIABILITY
E1 To the maximum extent permitted by law, 2x4’s total liability for any claims, whether in contract, tort, or otherwise, shall not exceed the lesser of $100,000 or ten times the value of the Fee paid. 2x4 shall not be liable for indirect, consequential, or economic loss, including loss of profit.
E2 2x4 shall not be liable to the Client for:
(i) the acts, omissions or defaults of inadequate brief from the Client or other contractors and/or consultants engaged by the Client (including consultants or contractors engaged by 2x4 as agent for the Client);
(ii) any changes, alterations or additions to the Services made by others without the express approval of 2x4;
(iii) any Services that are not performed in accordance with the Agreement, unless 2x4 is notified in writing of the non-performance within 1 year of the provision of those Services;
(iv) any loss of use, opportunity or production, loss of interest, earnings or profit, holding or financial costs, business interruption or any indirect or consequential losses;
(v) any loss, damage or claim to the extent that such loss, damage or claim was caused or contributed to by the Client or its employees, agents, consultants or contractors;
(vi) any financial cost to the Client for extra construction costs related to latent site conditions, unforeseen elements or general design improvements or alternative design solutions;
(vii) 2x4 accepts no liability for any new or pre-existing defects or Building Code and Australian Standards violations related to the current use of the Client’s asset;
(viii) 2x4 accepts no liability for temporary works required to allow occupation of the Client’s asset during and post construction and the Client retains full responsibility for this condition; and
E3 2x4 including its employees, agents, or sub-consultants shall not be liable for any claim in respect of the Services unless notified in writing within 12 months from the date of the final invoice, except where otherwise required by law. The client shall not be entitled to commence any action or claim whatsoever against 2x4 (or any employee, agent or sub-consultant of 2x4).
E4 If, and to the extent that, any of clauses E1, E2 or E3 is void as a result of the Australian Consumer Law, then 2x4’s liability for a breach of a condition or warranty is limited to the supplying of the relevant Services again or the payment of the cost of having the Services supplied again.
PART F – TERMINATION OF SERVICES / DISPUTES
F1 This Agreement may be terminated at any time by mutual Agreement in writing by the parties.
F2 If either party commits a substantial breach of this Agreement, the other party may give to the party who committed the breach a written notice to show cause. A notice to show cause must state that it is a notice given under this clause, specify the alleged breach with reasonable details, require the party who committed the breach to show cause in writing why the party giving notice should not terminate this Agreement and must specify a date (which must be not less than 10 Business Days after the notice is served) by which the party who committed the breach must show cause.
F3 Substantial breaches include suspension of work other than as permitted under this Agreement, failure to proceed with due care, skill and diligence and failure of the Client to pay 2x4 the Fee or any other amounts under this Agreement.
F4 If the recipient of a notice to show cause fails to show reasonable cause why the other party should not terminate this Agreement within the time specified in the notice, the other party may, by further written notice terminate this Agreement.
F5 Either party may terminate this Agreement without notice if the other party is subject to an Insolvency Event. This right is in addition to any other rights under this Agreement
F6 If this Agreement is terminated for any reason other than a breach of the Agreement by 2x4, the Client must pay to 2x4 the applicable portion of the Fee for the Services performed prior to the date of termination together with all Reimbursable Expenses incurred by 2x4 prior to the date of termination which would have been payable had the Agreement not been terminated.
F7 If within 28 days of the service of a notice of dispute, the parties cannot resolve the dispute the subject of that notice, then either party may refer the dispute to the Australian Disputes Centre for determination by expert determination in accordance with the Guidelines for Expert Determination of the Australian Disputes Centre.
F8 The costs of any independent person engaged to carry out the expert determination will, subject to any determination by the expert to the contrary, be borne by the parties equally. Each party must pay its own legal expenses in respect of the determination.
PART G – INTELLECTUAL PROPERTY RIGHTS
G1 All intellectual property created by 2x4 before the date of this Agreement remains vested in 2x4.
G2 All Intellectual Property Rights in all drawings, reports, specifications, bills of quantities, calculations and other documents or materials created by or for 2x4 in connection with the Services shall remain vested in 2x4 (2x4 Materials).
G3 2x4 grants the Client a non-exclusive, non-transferrable, royalty-free license to use, reproduce, and publish the 2x4 Materials for the purposes of completing the Project. The Client may not modify, adapt, or distribute the Materials without 2x4’s prior written consent.
G4 The Client grants 2x4 an irrevocable, royalty free licence to use and manipulate all Intellectual Property Rights in any information, documents and other particulars which the Client provides to 2x4 to the extent reasonably necessary for 2x4 to perform the Services.
PART H – SPECIALIST ASSISTANCE
H1 If 2x4 considers it appropriate to do so, they may with or without the Client’s prior approval, which shall not be unreasonably withheld, engage another consultant to assist in specialist areas.
H2 Unless otherwise specified these costs will be treated as outgoings and they will be charged at cost plus 20%.
H3 The Client agrees to indemnify and keep indemnified 2x4 in respect of any fees, costs, expense and any claim (including all reasonable legal costs and expenses) whatsoever in relation to work performed by the consultant.
H4 By appointing a consultant, 2x4 does not assume a duty of care and give no warranty, guarantee or representation about the professional capacity, reliability of the consultant.
PART I – COMMENCEMENT OF AGREEMENT
This Agreement shall be deemed effective on and from the date of commencement of services by 2x4 or the date on which both parties have signed this Agreement, whichever is earlier.
PART J – NOTICES
J1 A notice required or permitted to be given by one party to the other under this Agreement must be in writing, signed by the party giving it or their duly appointed solicitor, and is deemed as being duly given if:
(i) personally delivered to that party;
(ii) sent by pre-paid post, addressed to the other party; or
(iii) transmitted by email, to the other party’s email address.
J2 A notice given to a party in accordance with this clause 16 is deemed to have been duly given and received:
(i) at the time of delivery;
(ii) on the second Business Day after the day on which it is posted; and
(iii) on the day of transmission, where the person giving the notice has received no indication in any form that the notice has not been received, however if such delivery is later than 4.00pm or not on a Business Day, at 9.00am on the next Business Day.
J3 The address of a party is the address or number set out in this Agreement or another address which that party may from time to time give notice of to the other party.
PART K – CONFIDENTIALITY
K1 Each party agrees that it will not use Confidential Information in any way that might prejudice its confidentiality.
K2 The Confidential Information does not include information which:
(i) is generally available in the public domain otherwise than as a result of a breach of this Agreement; or
(ii) was known by the recipient party prior to the disclosing of the information to it.
K3 Despite this clause, either party may make such disclosures in relation this Agreement as is reasonably necessary:
(i) to its professional advisers upon those persons undertaking to keep confidential any information disclosed; or
(ii) to comply with any applicable law or the requirement of any regulatory body.
PART L – FORCE MAJEURE
L1 2x4 is not liable or in breach of this Agreement for any delays or failures in performance of this Agreement which result from circumstances beyond the reasonable control of 2x4.
L2 If such circumstances continue for a continuous period of more than 60 days, either party may terminate this Agreement by written notice to the other party.
PART M – MISCELLANEOUS
M1 This Agreement is governed by the laws of Tasmania, and the parties submit to the non-exclusive jurisdiction of the courts of Tasmania.
M2 This Agreement may not be varied or amended except in writing signed by the parties.
M3 If any provision of this Agreement is or becomes legally ineffective, under common law or legislation, the ineffective provision may be severed from this Agreement which otherwise continues to be valid and operational. The parties will agree on an arrangement having a legal and economic effect which will be as similar as possible to the ineffective provision.
M4 This Agreement does not create a relationship of employment, agency or partnership between the parties.
PART N – DEFINITIONS
Agreement means this Agreement for the provision of consulting engineering services and includes these Terms and Conditions and the Fee Submission Form.
Business Day means a day which is not a Saturday, Sunday or public holiday in Launceston, Tasmania.
Client means the client described in the Fee Submission Form.
Client Representative means the person appointed by the Client from time to time to act as the Client’s representative to exercise the Client’s functions under this Agreement.
Documentation means all information supplied to 2x4 by electronic or other means for the purposes of this Agreement.
Fee means the fee payable for the Services pursuant to the Fee Submission Form and does not include any additional fee for additional services.
Fee Submission Form means the form attached to this Agreement which outlines, among other things, the Services and the Fee.
Insolvency Event means any one or more of the following circumstances:
(i) either 2x4 or the Client informs the other party in writing or creditors generally that it is or may become insolvent, unable to pay its debts when due and payable or financially unable to proceed with this Agreement;
(ii) execution is levied against 2x4 or the Client by a creditor which is not satisfied, set aside or withdrawn within 14 days after execution is so levied;
(iii) 2x4 or the Client suspends payment of its debts;
(iv) the Client, being an individual person or a partnership including an individual person: commits an act of bankruptcy; has a bankruptcy petition presented against him or her or presents his or her own petition; is made bankrupt; makes a proposal for a scheme of arrangement or a composition; has a deed of assignment or deed of arrangement made, or accepts a composition; is required to present a debtor's petition; or has a sequestration order made under Part X of the Bankruptcy Act 1966 (Cth);
(v) 2x4 or the Client, being a corporation: enters into a deed of company arrangement, scheme of arrangement or composition with creditors; has (voluntarily or otherwise) a receiver, receiver and manager, controller or administrator, liquidator or provisional liquidator appointed to it; has a winding up order made against it or an application for a winding up order against it made to the court and not stayed within 14 days; resolves by special resolution that it be wound up voluntarily or placed under official management; or has any of its property taken possession of by a mortgagee.
Intellectual Property Rights includes property and rights in respect of or in connection with trademarks, patents, copyrights, processes know-how, registered designs or other like rights or any right to apply for registration of any of the former.
Project means the project carried out by the Client for which the Services form part of.
2x4 Representative means the person appointed by 2x4 from time to time to act as 2x4’s representative to exercise 2x4’s functions under this Agreement.
Reimbursable Expenses means all payments made to third parties which are necessary to enable 2x4 to carry out the Services.
Services means the works to be carried out by 2x4 for the Client in connection with the Project pursuant to the Fee Submission Form.